Legal · Document register
The terms governing App Clone Labs website use, project orders, scope, payment, delivery, intellectual property, warranties, and liability.
Document relationship
Terms & Conditions document context
Website policy provisions are read alongside project-specific statements of work and signed agreements.
Policy text · 16 sections
These Terms & Conditions govern use of appclonelabs.com, project enquiries, proposals, orders, and software-development services supplied by App Clone Labs. By using this website or ordering services, you agree to these terms. If you act for an organisation, you confirm that you have authority to bind it.
These terms sit alongside our End User Licence Agreement, Support Policy, Refund Policy, Privacy Policy, and Legal Notice & Disclaimer. If documents conflict, the order of precedence is: a signed master or project agreement; the applicable order, proposal, or statement of work; the End User Licence Agreement; these Terms & Conditions; then the other published policies.
You may use this website to evaluate our services and contact us. You may not use it unlawfully, misrepresent your identity or affiliation, interfere with its operation, gain unauthorised access, introduce harmful code, systematically extract content, or infringe another person’s rights.
Website descriptions and prices are informational and are not binding offers. A proposal is valid for the period stated in it and may be revised before acceptance. A contract is formed when we confirm an order in writing, sign an agreement, or receive the agreed initial payment, whichever the applicable project documents identify.
The written scope identifies deliverables, assumptions, exclusions, milestones, acceptance criteria, and responsibilities. Requests outside that scope require a written change approval and may affect fees, schedule, and architecture. Delivery dates depend on timely client access, content, feedback, approvals, third-party accounts, and decisions.
Fees, currency, milestones, deposits, and payment dates are stated in the order. Unless stated otherwise, taxes, duties, bank fees, exchange costs, cloud services, domains, app-store accounts, commercial licences, and usage-based third-party charges are paid by the client. We may pause work or access for overdue undisputed amounts after reasonable notice.
Delivery occurs when the agreed repository, package, credentials, deployment, design, documentation, or milestone is made available. The client must test deliverables within the acceptance period stated in the order and report reproducible material non-conformance against written criteria. Minor defects that do not prevent substantial use do not delay acceptance and will be handled under the agreed correction process.
Client-specific deliverables are assigned or licensed as stated in the order, normally after full payment. App Clone Labs retains pre-existing intellectual property, reusable frameworks, generic modules, methods, tools, know-how, and improvements that do not disclose client confidential information. Open-source and third-party components remain governed by their own licences.
Third-party products may be used descriptively to explain a category or functional reference. We do not promise rights to another company’s name, logo, content, design, private data, or proprietary code. Clients must supply lawful branding and content and are responsible for trademark clearance and operation of their launched business.
Each party must use the other party’s non-public information only for the engagement, protect it with reasonable care, and disclose it only to people who need it and are bound by appropriate duties. Personal data is handled under our Privacy Policy and any signed data-processing terms.
We perform services with reasonable care and skill. Except for commitments expressly written in the applicable agreement and to the fullest extent permitted by law, other warranties are excluded. We do not guarantee uninterrupted or error-free software, a commercial result, legal compliance in every jurisdiction, or approval by an app store, regulator, payment provider, hosting vendor, or other third party.
The client is responsible for claims arising from client-supplied branding, content, data, instructions, unlawful operation, regulatory failures, breach of third-party terms, or use of deliverables outside the agreed scope. Any indemnity, defence procedure, and exclusions are subject to the applicable signed agreement and mandatory law.
To the fullest extent permitted by law, neither party is liable for indirect, incidental, special, punitive, or consequential loss, or lost profit, revenue, goodwill, data, or opportunity. App Clone Labs’ aggregate liability connected with an engagement will not exceed the fees paid for the affected deliverable during the six months before the event giving rise to the claim, except where liability cannot lawfully be limited.
Either party may terminate for a material breach that remains uncured after reasonable written notice. We may suspend work for overdue payment, unsafe access, unlawful instructions, or material security risk. Neither party is liable for delay caused by events beyond reasonable control, but payment remains due for completed work and committed third-party costs.
The parties should first attempt to resolve disputes through good-faith written escalation. These terms are governed by the laws of India and, subject to mandatory rights and any arbitration clause in a signed agreement, courts in Mumbai, Maharashtra have exclusive jurisdiction. Invalid provisions are limited or severed without affecting the remainder; delay in enforcing a right is not a waiver; and no partnership, agency, or employment relationship is created.
Legal contact route
Contact our legal and compliance desk. Please include the relevant URL and enough detail for us to review the matter.
legal@appclonelabs.com